Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018

Transcription

1 75 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Ann Road, Clark County 215 Beltway to Durango Drive 1 97 RTC Number 107D ILC Amount $1,000, ILC Executed 08/13/2015 ILC Expiration 06/30/2020 Streets: TBD Scope Name: Bid Status In Design Bid Number Ann Road, Clark County 215 Beltway to Durango Drive Roadway widening to include minimum of two through lanes in each direction and a center two-way left turn lane.? 40% 37% 929 Feb 2018 Jinxin Xie May 2018 CCPW Design Mike Mamer Jun 2018 Aug 2018 May 2019 Arnona Road, Lake Mead Boulevard to Alto Avenue RTC Number 202-FTI ILC Amount $1,000, ILC Executed 12/14/2017 ILC Expiration 06/30/2022 Streets: NA Scope Name: Bid Status Front Ends Recd Arnona Road, Lake Mead Boulevard to Alto Avenue Construction of a new 32' wide paved road across undeveloped land. Work includes excavation, paving, cut-off walls, signing and striping. Bid Number % 0% 758 Nov 2017 Joe Yatson Jan 2018 CCPW Design Mike Mamer Feb 2018 Apr 2018 Jul 2018 Page 1 of 29

2 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Arterial Maintenance Fiscal Year RTC Number 135W-SB5 ILC Amount $586, ILC Executed 05/18/2017 ILC Expiration 06/30/2022 Streets: NA Scope Name: Bid Status Construction Bid Number Mt. Hood, Treeline and Various Neighborhood Streets Rehab Reconstruction of Mount Hood/Fogg Street, Bonanza Road to Lake Mead Drive; Tree Line Drive, Sahara Avenue to Charleston Boulevard; and on various residential streets within the Sunrise Valley and La Miranda neighborhoods % 41% 950 Dec 2016 Joe Yatson GCW, Inc. Apr /6/17 Robert McNamara CCPW Las Vegas Paving Corporation Jun /12/17 Sep /18/17 Feb 2018 Arterial Maintenance Fiscal Year RTC Number 135R ILC Amount $12,000, ILC Executed 09/12/2013 ILC Expiration 07/01/2018 Streets: Sidewalk ramps will be reconstructed and locations with missing sidewalk will be connected with an asphalt sidewalk. Scope Name: Bid Status Bid Number Kathleen G.C. Wallace, Blair Lecker CCPW Las Vegas Paving Pecos Road and Russell Road Resurfacing Kingston Inc. Corporation 100% 93% Mill & Overlay Pecos Road, Sunset Road to Flamingo Road, Russell Road, Mt Vista Road to City of Henderson, and Russell Road, Decatur Boulevard to Polaris Road 828 Jul 2014 Feb /11/15 Mar /20/15 Jul /10/15 Jul /29/16 32 RTC Number ILC Amount ILC Executed ILC Expiration Streets: Sidewalk ramps will be reconstructed and sidewalk repairs will be connected as needed. Scope Name: Bid Status Warranty Period Bid Number Kathleen Louis Berger Bermuda, Cabana, and McLeod Resurfacing Kingston Group P&P,R&R & M&O: Bermuda Road, Hidden Wells Road to Sunset Road, Cabana Drive, Flamingo Road to Vegas Valley Drive, McLeod Drive, Tropicana Road to Flamingo Road, Paradise & UPRR fix pavement 100% 97% 858 Aug Dec /8/15 Blair Lecker CCPW Las Vegas Paving Corporation Feb /5/16 Jun /6/16 May /4/17 Page 2 of 29

3 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Bunkerville Roads RTC Number 062F-FTI ILC Amount $44, ILC Executed 02/11/2016 ILC Expiration 06/30/2021 Streets: Scope Name: Bid Status Reconcile Bunkerville Roads: White Rock and Elbow Canyon Bid Number Resurfacing improvements to White Rock Road (Lime Klin Canyon Road) and Elbow Canyon Road-From existing pavement on White Rock, along White Rock and Elbow Canyon Road to the Nevada/Arizona Stateline or to a point on Elbow Canyon Road where funding for pavement is exhausted Streets: NA Scope Name: Bid Status Reconcile Bunkerville Roads: White Rock and Elbow Canyon Bid Number Resurfacing improvements to White Rock Road (Lime Klin Canyon Road) and Elbow Canyon Road-From existing pavement on White Rock, along White Rock and Elbow Canyon Road to the Nevada/Arizona Stateline or to a point on Elbow Canyon Road where funding for pavement is exhausted % 99% 761 Jan % 99% 761 Jan 2016 John Catanese Kimley-Horn & Assoc, Inc. Jun /28/16 John Catanese Kimley-Horn & Assoc, Inc. Jun /28/16 Blair Lecker CCPW Las Vegas Paving Corporation Aug /12/16 Feb /21/17 Apr /21/17 9 RTC Number 062F-SB5 ILC Amount $141, ILC Executed 08/12/2010 ILC Expiration 06/30/2020 Streets: Scope Name: Bid Status Reconcile Bunkerville Roads: White Rock and Elbow Canyon Bid Number Resurfacing improvements to White Rock Road (Lime Klin Canyon Road) and Elbow Canyon Road-From existing pavement on White Rock, along White Rock and Elbow Canyon Road to the Nevada/Arizona Stateline or to a point on Elbow Canyon Road where funding for pavement is exhausted % 99% 761 Jan 2016 John Catanese Kimley-Horn & Assoc, Inc. Blair Lecker CCPW Las Vegas Paving Corporation Aug /12/16 Feb /21/17 Apr /21/ RTC Number 062F ILC Amount $285, ILC Executed 02/11/2016 ILC Expiration 06/30/2021 Jun /28/16 Blair Lecker CCPW Las Vegas Paving Corporation Aug /12/16 Feb /21/17 Apr /21/17 Page 3 of 29

4 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Bunkerville Roads RTC Number 062F ILC Amount $781, ILC Executed 02/11/2016 ILC Expiration 06/30/2021 Streets: Scope Name: Bid Status Reconcile Bunkerville Roads: White Rock and Elbow Canyon Bid Number Resurfacing improvements to White Rock Road (Lime Klin Canyon Road) and Elbow Canyon Road-From existing pavement on White Rock, along White Rock and Elbow Canyon Road to the Nevada/Arizona Stateline or to a point on Elbow Canyon Road where funding for pavement is exhausted % 99% 761 Jan 2016 John Catanese Kimley-Horn & Assoc, Inc. Jun /28/16 Blair Lecker CCPW Las Vegas Paving Corporation Aug /12/16 Feb /21/17 Apr /21/17 Page 4 of 29

5 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Cactus Avenue, Rainbow Boulevard to Spencer Street 9 8 RTC Number 147A ILC Amount $48,996, ILC Executed 11/10/2004 ILC Expiration 07/01/2020 Streets: Scope Name: Bid Status Duck Creek Railroad Detention Basin Embankments for UPRR crossing Bid Number Design 100% 582 Bid 100% Mona Stammetti G.C. Wallace, Inc. Mar /4/09 Blair Lecker Nevada By Design Wells Cargo, Inc. Sep /9/09 Nov /30/09 Feb /1/11 46 RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status Cactus Avenue/ Union Pacific Railroad (UPRR) Grade Separation Full improvements along Cactus Avenue, Rainbow Boulevard to Verona Wood Street, including bridge structure over UPRR. Bid Number Design 100% 679 Bid 94% Mona Stammetti Atkins Aug /22/13 Mike Mamer CH2M Hill, Inc. Las Vegas Paving Corporation Oct /31/13 Mar /24/14 Dec /26/14 26 RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status Cactus Avenue and I-15 Interchange Bid Number I-15 at Cactus Avenue interchange in Las Vegas NDOT will construct interchange and traffic signal at LVB. CCPW continues coordination through construction. NDOT 3530 Design 100% 680 Bid Roy Davis Louis Berger Group Nov /9/12 NDOT (LVP) 11/15/12 4/2/13 Oct /29/14 Page 5 of 29

6 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Cactus Avenue, Rainbow Boulevard to Spencer Street 9 27 RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status In Design Outbound Airport Express Bid Number Elevated expressway from McCarran to Resort Corridor? 15% 0% 773 May 2019 Joe Yatson Aug 2019 CH2M Hill, Inc. Mike Mamer Sep 2019 Dec 2019 Dec RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status Warranty Period Cactus Avenue/ Union Pacific Railroad (UPRR) Grade Separation Full improvements to Cactus Avenue,Valley View Boulevard to Dean Martin Drive Bid Number CO# % 100% 774 Apr 2014 Roy Davis Aug 2014 Louis Berger Group Mike Mamer CH2M Hill, Inc. Las Vegas Paving Corporation Sep 2014 Aug /20/14 Dec /26/14 29 RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status In Design Cactus Avenue, Verona Wood Street to Valley View Boulevard Bid Number Full improvements to Cactus/ UPRR touchdown to Valley View Boulevard? 90% 0% 775 May 2018 Brooke Prescia Aug 2018 CH2M Hill Engineers, Inc. Mike Mamer TBD Sep 2018 Dec 2018 Sep 2019 Page 6 of 29

7 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Cactus Avenue, Rainbow Boulevard to Spencer Street 9 30 RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status In Design Cactus Avenue, LVB to Spencer St & Haven Storm Drain Full improvements to Cactus Avenue, Las Vegas Boulevard to Spencer Street Bid Number? 90% 0% 776 Feb 2018 Roy Davis May 2018 Atkins Mike Mamer TBD Jun 2018 Sep 2018 Jun RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status In Design Inbound Airport Express Bid Number Elevated expressway from Resort Corridor to McCarran? 10% 0% 777 May 2019 Joe Yatson Jul 2019 Louis Berger Group Mike Mamer Aug 2019 Nov 2019 Nov RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status Bid Number Traffic Signals at Cactus Avenue/ Jones and Rainbow Construct new traffic signal and other improvements including additional paving, crosswalks, signs, and pavement markings at the intersection of Cactus Avenue and Jones Boulevard % 100% 921 Sep 2014 Brooke Prescia CH2M Hill, Inc. Jan /9/15 Mathew Burke CCPW Fast Trac Electric Feb /20/15 May /18/15 Jul /16/15 Page 7 of 29

8 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Carey Avenue, Nellis Boulevard to Toiyabe Street 2 79 RTC Number 016H-FTI ILC Amount $200, ILC Executed 08/14/2014 ILC Expiration 06/30/2019 Streets: NA Scope Name: Bid Status In Design Carey Avenue, Nellis Boulevard to Toiyabe Street Bid Number Full improvements up to four lanes for Carey Avenue, Nellis Boulevard to Toiyabe Street and bridge over Sloan Channel.? 6% 0% 862 Nov 2018 John Catanese Feb 2019 Louis Berger Group Mike Mamer CCPW Mar 2019 May 2019 Nov RTC Number 016H ILC Amount $3,220, ILC Executed 08/18/2013 ILC Expiration 07/01/2018 Streets: NA Scope Name: Bid Status In Design Carey Avenue, Nellis Boulevard to Toiyabe Street Bid Number Full improvements up to four lanes for Carey Avenue, Nellis Boulevard to Toiyabe Street and bridge over Sloan Channel.? 6% 0% 862 Nov 2018 John Catanese Feb 2019 Louis Berger Group Mike Mamer CCPW Mar 2019 May 2019 Nov 2020 Casa Linda and Pebble Canyon Neighborhood Street Rehabilitation 1 61 RTC Number 175D-FTI ILC Amount $2,250, ILC Executed 08/14/2014 ILC Expiration 06/30/2019 Streets: Bring sidewalk ramps up to ADA standards Scope Name: Bid Status Warranty Period Bid Number Casa Linda, Craig Park, and Pebble Canyon Pulverize and Pave Pavement rehabilitation 100% 96% 870 Mar 2016 Richard Robinson CCPW Design Jun /28/16 Blair Lecker CCPW Aggregate Industries SWR Inc. Jul /29/16 Jan /3/17 Apr /3/17 Page 8 of 29

9 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 CC-215, Decatur Boulevard to North 5th Street 1 38 RTC Number 076V-FTI ILC Amount $43,150, ILC Executed 10/10/2013 ILC Expiration 07/01/2018 Streets: NA Scope Name: Bid Status Sub North CC-215 Beltway, Decatur to North 5th Full Improvements BW, Decatur to North 5th full improvements, including roadway, drainage and utility improvements. Bid Number % 94% 722 Sep 2013 Roy Davis VTN Nevada Dec /2/13 Blair Lecker CM Works, Inc. Las Vegas Paving Corporation Jun /27/14 Nov /3/14 Nov /28/16 CC-215, Airport Connector Phase II 1 51 RTC Number 076Y-FTI ILC Amount $29,500, ILC Executed 05/15/2014 ILC Expiration 07/01/2019 Streets: NA Scope Name: Bid Status Sub I-215, Airport Connector Phase 2 Bid Number Build a direct connection (flyover) for southbound traffic from the airport tunnel southerly approach to I-215 eastbound. Reconstruct southern airport connector ramp to Warm Springs Road % 99% 917 Apr 2014 Spring Dineen Parsons Brinckerhoff, Inc. Mar /6/15 Robert McNamara HDR Las Vegas Paving Engineering, Corporation Inc. Apr /9/15 Aug /3/15 Aug /29/17 CC-215, Grand Montecito Pkwy Bridge 1 52 RTC Number 076Z-FTI ILC Amount $10,163, ILC Executed 09/10/2015 ILC Expiration 06/30/2020 Streets: Will not be included due to freeway classification Scope Name: Bid Status Reconcile Bid Number Brooke Prescia R2H Luis Lavayen Louis Berger Las Vegas Paving CC-215, Grand Montecito Parkway Bridge Engineering, Group Corporation Inc. 100% 100% Construct a concrete bridge on CC 215, approximately 160 long x 65 wide, crossing over Grand Montecito Pkwy from Durango Drive to Oso Blanca Road carrying traffic east bound. This bridge is a mirror image of existing bridge at this location that will be converted to west bound only. 751 Aug 2015 Nov /10/15 Dec /9/15 May /16/16 Jun /10/17 Page 9 of 29

10 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Streets: Desert Inn Road, Sir George Drive, and Winterwood Boulevard 1 92 RTC Number 176B-FTI ILC Amount ILC Executed 05/21/2015 ILC Expiration 03/30/2020 Streets: Desert Inn, Lamb to Nellis - Curb, gutter, sidewalk and streetlights. Sir George Drive - decorative medians Scope Name: Bid Status Reconcile Bid Number Spring Dineen Atkins Blair Lecker CCPW Unicon, LLC Desert Inn Road, Sir George Drive and Winterwood Boulevard Desert Inn, Lamb to Nellis - full street improvs. Sir George, Nellis -Stewart - remove med island & replace with stained exposed rock concrete. Winterwood, Club House to Sahara - remove & replace asphalt pavement : QC Deficiency 100% 99% 920 Sep Oct /28/ Aug /26/16 Jan /24/17 Jun /13/17 Craig Park and Paradise Palms Neighborhood Street Rehabilitation 1 64 RTC Number ILC Amount $3,800, ILC Executed 11/13/2014 ILC Expiration 06/30/2019 Streets: Bring sidewalk ramps up to ADA standards. Scope Name: Bid Status Reconciliation Bid Number Paradise Palms Neighborhood Street Rehabilitation Pavement rehabilitation 100% 100% 873 Jun 2016 Richard Robinson CCPW Design Sep /1/16 Luis Lavayen CCPW CG&B Enterprises, Inc. Sep /30/16 Mar /6/17 Sep /30/17 Page 10 of 29

11 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Decatur Boulevard, Cactus Avenue to Warm Springs Road 3 66 RTC Number 007M-FTI ILC Amount $350, ILC Executed 07/10/2014 ILC Expiration 07/01/2019 Streets: NA Scope Name: Bid Status In Design Decatur Boulevard, Cactus Avenue to Warm Springs Road Improvements to Decatur Boulevard, Cactus Avenue to Warm Springs Road. The improvements may include up to four travel lanes Bid Number? 60% 0% 869 Apr 2018 Mona Stammetti Jul 2018 Stanley Consultants, Inc. Mike Mamer Aug 2018 Nov 2018 May RTC Number 007M ILC Amount $850, ILC Executed 08/18/2013 ILC Expiration 07/01/2018 Streets: NA Scope Name: Bid Status In Design Decatur Boulevard, Cactus Avenue to Warm Springs Road Improvements to Decatur Boulevard, Cactus Avenue to Warm Springs Road. The improvements may include up to four travel lanes Bid Number? 60% 0% 869 Apr 2018 Mona Stammetti Jul 2018 Stanley Consultants, Inc. Mike Mamer Aug 2018 Nov 2018 May RTC Number 007M ILC Amount $2,547, ILC Executed 08/14/2014 ILC Expiration 06/30/2019 Streets: NA Scope Name: Bid Status In Design Decatur Boulevard, Cactus Avenue to Warm Springs Road Improvements to Decatur Boulevard, Cactus Avenue to Warm Springs Road. The improvements may include up to four travel lanes Bid Number? 60% 0% 869 Apr 2018 Mona Stammetti Jul 2018 Stanley Consultants, Inc. Mike Mamer Aug 2018 Nov 2018 May 2020 Page 11 of 29

12 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Desert Inn Road, Cabana Drive to Hollywood Boulevard RTC Number 054G ILC Amount $4,500, ILC Executed ILC Expiration 06/30/2021 Streets: Bike lanes and sidewalk Scope Name: Bid Status In Number? Mona Atkins Mike Mamer Desert Inn Road, Nellis Boulevard to Hollywood Stammetti Boulevard 60% 0% Feb 2018 May 2018 Jun 2018 Sep 2018 Jun 2019 Durango Drive, Blue Diamond Road to Windmill Lane 2 14 RTC Number 070J-SB5 ILC Amount $600, ILC Executed 06/10/2010 ILC Expiration 06/30/2020 Streets: Curbs, gutters, sidewalks, pavement, and streetlights Scope Name: Bid Status In Number? Durango Drive, Blue Diamond Road to Windmill Lane Improvements to Durango Drive, Blue Diamond Road to Windmill Lane 90% 0% 732 Feb 2018 Brooke Prescia May 2018 HDR Engineering, Inc. Mike Mamer TBD Jun 2018 Sep 2018 Apr RTC Number 070J ILC Amount $5,800, ILC Executed 07/10/2014 ILC Expiration 07/01/2019 Streets: Curbs, gutters, sidewalks, pavement, and streetlights Scope Name: Bid Status In Number? Durango Drive, Blue Diamond Road to Windmill Lane Improvements to Durango Drive, Blue Diamond Road to Windmill Lane 90% 0% 732 Feb 2018 Brooke Prescia May 2018 HDR Engineering, Inc. Mike Mamer TBD Jun 2018 Sep 2018 Apr 2019 Page 12 of 29

13 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Durango Drive, Warm Springs Road to Sahara Avenue ITS 1 55 RTC Number 144Q ILC Amount $1,556, ILC Executed 06/13/2013 ILC Expiration 07/01/2018 Streets: NA Scope Name: Bid Status Reconciliation Durango Drive & Tropicana Avenue Fiber Optic Interconnect Systems Bid Number ITS infrastructure on Durango Drive from the Warm Springs Road to Sahara Avenue % 99% 849 Jun 2015 Jimmy Benoit C-A Group Sep /14/15 Robert McNamara CCPW TransCore ITS, LLC Nov /2/15 Mar /11/16 Feb /9/17 Page 13 of 29

14 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Eastern Avenue, Warm Springs Road to Desert Inn Road RTC Number ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status In Design Eastern Avenue, Sunset Road to Desert Inn Road Bid Number? 0% 0% 883 Apr 2018 Spring Dineen Jul 2018 TBD Mike Mamer Aug 2018 Nov 2018 May RTC Number ILC Amount ILC Executed ILC Expiration Streets: NA Scope Name: Bid Status Front Ends Recd Bid Number Eastern Avenue, Warm Springs Road to Sunset Road Roadway improvements on Eastern Avenue, Warm Spring Road to Sunset Road % 0% 934 Dec 2016 Spring Dineen Jan 2018 C-A Group Mike Mamer TBD Feb 2018 May 2018 Aug RTC Number 002AB-FTI ILC Amount $6,250, ILC Executed 10/13/2016 ILC Expiration 06/30/2021 Streets: Existing Scope Name: Bid Status Construction Bid Number Eastern Avenue, Tompkins Avenue to Flamingo Road With CCWRD Bid 735: 1-inch mill and UTACS of pavement on Eastern Ave, removal and replacement on failed pavement within the project limits, bring all substandard ADA ramps up to current standards CCWRD % 75% 945 Sep 2016 Spring Dineen CCWRD Oct /18/16 Dan Erickson CCPW CCWRD Dec /15/16 Jun /11/17 Jun 2018 Page 14 of 29

15 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Eastern Avenue, Warm Springs Road to Desert Inn Road RTC Number ILC Amount ILC Executed ILC Expiration Streets: Concrete bus pads will be proposed at transit stops with high ridership. Scope Name: Bid Status ed Bid Number Joe Yatson GCW, Inc. Blair Lecker Las Vegas Paving Eastern Avenue and Maryland Parkway Rehabilitation Corporation 100% 0% Rehabilitation for Eastern Avenue, Flamingo Road to Desert Inn Road and Maryland Parkway, Flamingo Road to Twain Avenue. 956 Apr 2017 Sep /12/17 Oct /30/17 Jan 2018 May 2018 Eastern Avenue, Wigwam Parkway to Warm Springs Road 1 50 RTC Number 002AA-FTI ILC Amount $2,100, ILC Executed 05/21/2015 ILC Expiration 06/30/2020 Streets: NA Scope Name: Bid Status Sub Bid Number Eastern Avenue: Wigwam to Wm Spgs, Serene to BW, & I-215 Ramps Full improvements on Eastern Avenue, however pavement is in need of rehabilitation and ADA ramps are not up to standard. Eastern Avenue pavement section includes 3 travel lanes in each direction and a center turn lane % 96% 823 Sep 2015 Spring Dineen C-A Group Oct /27/15 Blair Lecker CCPW Aggregate Industries SWR Inc. Mar /10/16 Apr /21/17 Oct /29/17 Fort Apache Road, Alexander Road to CC RTC Number 113C-FTI ILC Amount $1,200, ILC Executed ILC Expiration 06/30/2022 Streets: NA Scope Name: Bid Status In Design Fort Apache Road, Lone Mountain Road to CC-215 Bid Number? 0% 0% 933 Jul 2018 Roy Davis Oct 2018 Horrocks Engineers, Inc. Mike Mamer TBD Nov 2018 Feb 2019 Feb 2020 Page 15 of 29

16 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Fort Apache Road, Warm Springs Road to Tropicana Avenue 1 73 RTC Number 113B-FTI ILC Amount $12,400, ILC Executed 05/19/2016 ILC Expiration 06/30/2021 Streets: Bike lanes; construct new sidewalks; reconstruct sidewalk ramps to ADA standards and repair sidewalks and curb and gutter as needed. Scope Name: Bid Status In Number? Kathleen Poggemeyer Mike Mamer Poggemeyer Fort Apache Road, Warm Springs Road to Tropicana Kingston Design Group, Design Avenue Inc. Group, Inc. Widen to 4 lanes 60% 0% 841 Jul Oct Nov 2018 Jan 2019 Oct 2019 Hollywood Boulevard, Charleston Boulevard to Lake Mead Boulevard 1 15 RTC Number 099C ILC Amount $4,000, ILC Executed 09/12/2013 ILC Expiration 07/01/2018 Streets: Separated path, bike lanes Scope Name: Bid Status In Number Hollywood Boulevard, Charleston Boulevard to Lake Mead Boulevard Improvements to Hollywood Boulevard, Charleston Boulevard to Lake Mead Boulevard. The improvements may include up to four travel lanes? 90% 0% 894 Sep 2017 Jinxin Xie Feb 2018 CCPW Design Mike Mamer CCPW Mar 2018 Jun 2018 Oct 2018 Page 16 of 29

17 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Jones Boulevard, Blue Diamond Road to Windmill Lane RTC Number 033Q-FTI ILC Amount $12,808, ILC Executed 02/11/2016 ILC Expiration 06/30/2021 Streets: Sidewalk Scope Name: Bid Status In Design Jones Boulevard, Blue Diamond Road to Windmill Lane Widen to 4 lanes, bridge structure at UPRR Bid Number? 90% 0% 872 Jul 2018 John Catanese Oct 2018 R2H Engineering, Inc. Mike Mamer TBD Nov 2018 Feb 2019 Feb RTC Number 033Q-FTI ILC Amount ILC Executed ILC Expiration Streets: NA Scope Name: Bid Status Front Ends Recd Traffic Signal Improvements: Jones Boulevard and Windmill Lane Bid Number Constlruct a traffic signal at Jones Boulevard and Windmill Lane % 0% 963 Aug 2017 John Catanese Jan 2018 R2H Engineering, Inc. Mike Mamer TBD Feb 2018 Jul 2018 Aug 2018 Jones Boulevard, Cactus Avenue to Blue Diamond Road RTC Number 033R ILC Amount $4,800, ILC Executed 07/14/2016 ILC Expiration 06/30/2021 Streets: Curb, gutter, sidewalk, streetlights in front of the future CC Public Works facility near Pyle. Scope Name: Bid Status Advertising Bid Number Brooke Prescia Parsons Jones Boulevard, Pyle Avenue to Blue Diamond Road Brinckerhoff, Inc. 100% 0% 928 Aug 2017 Dec /29/17 Mike Mamer CCPW Feb 2018 May 2018 Sep 2018 Page 17 of 29

18 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Las Vegas Boulevard, St. Rose Parkway to Silverado Ranch Boulevard 1 68 RTC Number 089E-FTI ILC Amount $12,000, ILC Executed 08/14/2014 ILC Expiration 06/30/2019 Streets: Potential bike lanes in ultimate buildout, right-of-way width to accommodate wider sidewalks with buffers and potential for future transit. Scope Name: Bid Status Construction Bid Number Spring Dineen G.C. Wallace, Robert Las Vegas Paving Inc. McNamara Corporation Las Vegas Boulevard, St. Rose Parkway - Silverado Ranch Boulevard Widen to 3 lanes each direction with median islands, signing, striping and drainage : ing to determine if SID Design Bid 100% 64% 686 Aug May /27/ URS Consultants, Inc Oct /14/16 Apr /3/17 Apr 2018 Lone Mountain Road, Clark County 215 Beltway to Tenaya Way 2 98 RTC Number 165B ILC Amount $5,050, ILC Executed 08/13/2015 ILC Expiration 06/30/2020 Streets: Yes Scope Name: Bid Status Advertising Lone Mountain Road, Clark County 215 Beltway to Tenaya Way Bid Number Roadway widening to include minimum of two through lanes in each direction and a center two-way left turn lane % 0% 930 Aug 2017 Spring Dineen C-A Group Dec /1/17 Luis Lavayen Jan 2018 Mar 2018 Dec RTC Number 165B-FTI2 ILC Amount $16,250, ILC Executed 09/14/2017 ILC Expiration 06/30/2022 Streets: Scope Name: Bid Status Advertising Lone Mountain Road, Clark County 215 Beltway to Tenaya Way Bid Number Roadway widening to include minimum of two through lanes in each direction and a center two-way left turn lane % 0% 930 Aug 2017 Spring Dineen C-A Group Dec /1/17 Luis Lavayen Jan 2018 Mar 2018 Dec 2018 Page 18 of 29

19 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Maryland Parkway, Russell Road to Twain Avenue 2 69 RTC Number 003Y-FTI ILC Amount $7,014, ILC Executed 02/11/2016 ILC Expiration 06/30/2021 Streets: Upgrade sidewalk ramps to be ADA compliant. Scope Name: Bid Status In Number? Richard CCPW Design Mike Mamer CCPW Robinson Maryland Parkway, Russell Road to Twain Avenue Resurfacing Design Bid 90% 0% 907 Jan Apr May 2018 Jul 2018 Nov RTC Number ILC Amount ILC Executed ILC Expiration Streets: Increase safety of pedestrians with this signal. Scope Name: Bid Status Sub Bid Number Pedestrian Signal System at Del Mar Street and Maryland Parkway Pedestrian Signal System at Maryland/Del Mar; median island modification; sidewalk ramp relocation/reconstruction; coordination with UNLV to align crosswalk/walkway. 100% 82% 944 May 2017 Jimmy Benoit Louis Berger Group Jun /13/17 Blair Lecker Fast Trac Electric Jul /7/17 Oct /1/17 Oct /30/17 Page 19 of 29

20 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Moapa Town Roads II RTC Number 069E-FTI ILC Amount $199, ILC Executed 07/14/2016 ILC Expiration 06/30/2021 Streets: Scope Name: Bid Status Warranty Period Moapa Town Roads II: Henrie Road Bid Number Roadway rehabilitation to existing roads within the Moapa Town Township % 99% 768 Jun 2016 Timothy Piparo CCPW Design Oct /26/16 Robert McNamara CCPW Meadow Valley s, Inc. Nov /30/16 Mar /14/17 Aug /29/17 58 RTC Number 069E-SB5 ILC Amount $310, ILC Executed 04/10/2014 ILC Expiration 07/01/2019 Streets: Scope Name: Bid Status Warranty Period Moapa Town Roads II: Henrie Road Bid Number Roadway rehabilitation to existing roads within the Moapa Town Township % 99% 768 Jun 2016 Timothy Piparo CCPW Design Oct /26/16 Robert McNamara CCPW Meadow Valley s, Inc. Nov /30/16 Mar /14/17 Aug /29/ RTC Number 069E ILC Amount $629, ILC Executed 07/14/2016 ILC Expiration 06/30/2021 Streets: Scope Name: Bid Status Warranty Period Moapa Town Roads II: Henrie Road Bid Number Roadway rehabilitation to existing roads within the Moapa Town Township % 99% 768 Jun 2016 Timothy Piparo CCPW Design Oct /26/16 Robert McNamara CCPW Meadow Valley s, Inc. Nov /30/16 Mar /14/17 Aug /29/17 Page 20 of 29

21 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Moapa Town Roads II 4 17 RTC Number 069E ILC Amount $1,271, ILC Executed 03/11/2010 ILC Expiration 06/30/2021 Streets: 8 sidewalk offset 6 from East edge of proposed pavement between Patriots Way and Isola Drive. Scope Name: Bid Status Warranty Period Bid Number Timothy Piparo CCPW Design Robert CCPW Meadow Valley Moapa Town Roads II: Henrie Road McNamara s, Inc. 100% 99% Roadway rehabilitation to existing roads within the Moapa Town Township. 768 Jun 2016 Oct /26/16 Nov /30/16 Mar /14/17 Aug /29/17 Page 21 of 29

22 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Moapa Valley Roads VI 3 82 RTC Number 068K-SB5 ILC Amount $31, ILC Executed 10/09/2014 ILC Expiration 06/30/2019 Streets: Scope Name: Bid Status Reconcile Bid Number Moapa Valley Roads VI 100% 96% Lewis Avenue, Moapa Valley Boulevard to Deer Street. Deer Street, Lewis Avenue to the Overton Park.Rice Street, Wittwer Avenue to Brothers Avenue. St. Joseph Street, Cram Avenue to Bunnell Avenue. Wittwer Avenue Ash 792 Feb 2016 Street to Yamashita Street. Bunnell Avenue Heyer Street to St. Joseph Street (DELETED) Streets: Scope Name: Bid Status Reconcile Bid Number Moapa Valley Roads VI 100% 96% Lewis Avenue, Moapa Valley Boulevard to Deer Street. Deer Street, Lewis Avenue to the Overton Park.Rice Street, Wittwer Avenue to Brothers Avenue. St. Joseph Street, Cram Avenue to Bunnell Avenue. Wittwer Avenue Ash 792 Feb 2016 Street to Yamashita Street. Bunnell Avenue Heyer Street to St. Joseph Street (DELETED) John Catanese Kimley-Horn & Assoc, Inc. Jun /17/16 John Catanese Kimley-Horn & Assoc, Inc. Jun /17/16 Blair Lecker Horrocks Mel Clark, Inc. Jul /29/16 Feb /13/17 May /2/17 91 RTC Number 068K ILC Amount $999, ILC Executed 02/12/2015 ILC Expiration 06/30/2020 Streets: NA Scope Name: Bid Status Reconcile Bid Number Moapa Valley Roads VI 100% 96% Lewis Avenue, Moapa Valley Boulevard to Deer Street. Deer Street, Lewis Avenue to the Overton Park.Rice Street, Wittwer Avenue to Brothers Avenue. St. Joseph Street, Cram Avenue to Bunnell Avenue. Wittwer Avenue Ash 792 Feb 2016 Street to Yamashita Street. Bunnell Avenue Heyer Street to St. Joseph Street (DELETED) John Catanese Kimley-Horn & Assoc, Inc. Blair Lecker Horrocks Mel Clark, Inc. Jul /29/16 Feb /13/17 May /2/ RTC Number 068K ILC Amount $1,677, ILC Executed 03/10/2016 ILC Expiration 06/30/2021 Page 22 of 29 Jun /17/16 Blair Lecker Horrocks Mel Clark, Inc. Jul /29/16 Feb /13/17 May /2/17

23 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Outlying Area Roads 1 18 RTC Number 067B ILC Amount $163, ILC Executed 03/11/2010 ILC Expiration 06/30/2020 Streets: Scope Name: Bid Status Outlying Areas Slurry Seal 2010 Bid Number Slurry seal applied to roadways in the project areas: Urban Areas, Sunrise Mountain area, Blue Diamond, Indian Springs, Mt Charleston Design 100% 672 Bid 100% Kathleen Kingston CCPW Design 1/11/11 Blair Lecker CCPW American Pavement Preservation LLC Jan /27/11 Aug /8/11 Oct /27/11 Rainbow Boulevard, Cactus Avenue to Blue Diamond Road 1 20 RTC Number 010H-SB5 ILC Amount $450, ILC Executed 06/10/2010 ILC Expiration 06/30/2020 Streets: Curbs, gutters, sidewalks, pavement, and streetlights Scope Name: Bid Status Warranty Period Bid Number Rainbow Boulevard, Cactus Avenue to Blue Diamond Road Improvements to Rainbow Boulevard, Cactus Avenue to Blue Diamond Road 100% 100% 735 Jul 2015 Mona Stammetti VTN Nevada Oct /22/15 Luis Lavayen CCPW Aggregate Industries SWR Inc. Apr /15/16 Sep /26/16 Apr /12/17 Rainbow Boulevard, Erie Avenue to Blue Diamond Road RTC Number 010M-FTI ILC Amount $8,000, ILC Executed 07/10/2014 ILC Expiration 07/01/2019 Streets: NA Scope Name: Bid Status Warranty Period Bid Number Rainbow Boulevard, Cactus Avenue to Blue Diamond Road Improvements to Rainbow Boulevard, Cactus Avenue to Blue Diamond Road % 100% 735 Jul 2015 Mona Stammetti VTN Nevada Oct /22/15 Luis Lavayen CCPW Aggregate Industries SWR Inc. Apr /15/16 Sep /26/16 Apr /12/17 Page 23 of 29

24 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Rainbow Boulevard, Warm Springs Road to Tropicana Avenue 2 40 RTC Number 010K ILC Amount $800, ILC Executed 10/10/2013 ILC Expiration 07/01/2018 Streets: NA Scope Name: Bid Status Reconciliation Flamingo Diversion - Rainbow Branch and Rainbow Widening Widen Rainbow Boulevard, Warm Springs Road to Tropicana Avenue Bid Number id % 0% 716 Sep 2015 Richard Robinson CCPW Design May /15/15 Robert McNamara CH2M Hill, Inc. Las Vegas Paving Corporation Jul /10/15 Feb /16/16 Jun /7/ RTC Number 010K-FTI ILC Amount $4,100, ILC Executed 09/10/2015 ILC Expiration 06/30/2020 Streets: NA Scope Name: Bid Status Reconciliation Flamingo Diversion - Rainbow Branch and Rainbow Widening Widen Rainbow Boulevard, Warm Springs Road to Tropicana Avenue Bid Number id % 0% 716 Sep 2015 Richard Robinson CCPW Design May /15/15 Robert McNamara CH2M Hill, Inc. Las Vegas Paving Corporation Jul /10/15 Feb /16/16 Jun /7/17 Robindale Road, Cimarron Road, and Durango Drive RTC Number 115B ILC Amount $3,727, ILC Executed 02/09/2016 ILC Expiration 06/30/2022 Streets: Medians, shared outside lane Scope Name: Bid Status Construction Bid Number Robindale Road, Cimarron Road, and Durango Drive Southwest Regional Sports Park Offsites:Robindale Road, Durango Drive to Buffalo Drive; Cimarron Road, Robindale Road to Warm Springs Road; Durango Drive, Robindale Road to 1500' North of Robindale Road % 4% 941 Jan 2017 Timothy Piparo CCPW Design May /25/17 Blair Lecker Las Vegas Paving Corporation Jun /23/17 Nov /6/17 Jun 2018 Page 24 of 29

25 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Russell Road, Las Vegas Beltway to Rainbow Boulevard 2 62 RTC Number 008S ILC Amount ILC Executed ILC Expiration Streets: Scope Name: Bid Status In Design Bid Number Russell Road, Cimarron Road to Rainbow Boulevard Full improvements to Russell Road, Cimarron to Rainbow Boulevard? 90% 691 Sep 2017 Roy Davis Feb 2018 HDR Engineering, Inc. Mike Mamer TBD Mar 2018 Jun 2018 Jun RTC Number 008S ILC Amount $18,500, ILC Executed 07/11/2002 ILC Expiration 07/01/2022 Streets: Sidewalk and streetlights Scope Name: Bid Status In Number Russell Road, Cimarron Road to Rainbow Boulevard Full improvements to Russell Road, Cimarron to Rainbow Boulevard? 90% 691 Sep 2017 Roy Davis Feb 2018 HDR Engineering, Inc. Mike Mamer TBD Mar 2018 Jun 2018 Jun 2019 Sandy Valley: Columbia Pass Road & Miami Street 1 19 RTC Number 120A ILC Amount $994, ILC Executed 02/14/2002 ILC Expiration 06/30/2021 Streets: Scope Name: Bid Status Sandy Valley - Columbia Pass (CANCELLED) Bid Number Improvements to Miami Street (completed) and Columbia Pass (Sandy Valley, SR 161 to Cherokee St and Cherolee St, Sandy Valley to Quartz) Design 100% 778 Bid 0% Richard Robinson CCPW Design Dec /23/15 Mike Mamer CCPW Nov 2017 Feb 2018 Apr /1/40 Page 25 of 29

26 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Searchlight Roads II 2 35 RTC Number 061H-FTI ILC Amount $24, ILC Executed 08/13/2015 ILC Expiration 06/30/2020 Streets: Scope Name: Bid Status Reconciliation Bid Number Searchlight: Cottonwood Cove Road, US 95 to Michael Wendell Way Construct apprx 4000' of ADA accessible multi-use trail to increase bicycle/pedestrian safety and enhance multi-modal access to Harry Reid ES % 100% 913 Apr 2016 Jinxin Xie CCPW Design Oct /26/16 Luis Lavayen CCPW CG&B Enterprises, Inc. Nov /18/16 Jun /5/17 Sep /30/17 34 RTC Number 061H ILC Amount $290, ILC Executed 05/19/2016 ILC Expiration 06/30/2021 Streets: NA Scope Name: Bid Status Reconciliation Bid Number Searchlight: Cottonwood Cove Road, US 95 to Michael Wendell Way Construct apprx 4000' of ADA accessible multi-use trail to increase bicycle/pedestrian safety and enhance multi-modal access to Harry Reid ES % 100% 913 Apr 2016 Jinxin Xie CCPW Design Oct /26/16 Luis Lavayen CCPW CG&B Enterprises, Inc. Nov /18/16 Jun /5/17 Sep /30/17 Sunset Road, Rainbow Boulevard to Decatur Boulevard 1 89 RTC Number 008W ILC Amount $1,200, ILC Executed 12/11/2014 ILC Expiration 06/30/2019 Streets: NA Scope Name: Bid Status Warranty Period Bid Number Sunset Road, Jones Boulevard to Decatur Boulevard Widen 4 lanes, bridge structure at Army Corps "H" channel. Initial project from Westwind to Mohawk to bridge the Lower Blue Diamond Channel % 100% 877 Nov 2014 John Catanese G.C. Wallace, Inc. Mar /13/15 Robert McNamara CCPW Tand, Inc. Apr /16/15 Jun /29/15 Oct /15/15 Page 26 of 29

27 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Sunset Road, Rainbow Boulevard to Decatur Boulevard 1 78 RTC Number 008W-FTI ILC Amount $200, ILC Executed 12/11/2014 ILC Expiration 06/30/2019 Streets: NA Scope Name: Bid Status In Design Sunset Road, Rainbow Boulevard to Decatur Boulevard Widening Build to 4 lanes Bid Number? 0% 0% 927 Dec 2018 John Catanese Mar 2019 TBD Mike Mamer Apr 2019 Jul 2019 Jul 2020 Traffic Improvements at Lake Mead Boulevard and Sloan Lane 1 59 RTC Number 050N-FTI ILC Amount $919, ILC Executed 06/12/2014 ILC Expiration 07/01/2019 Streets: Installation of signal will improve safety for pedestrians visiting the park and improvements for south leg of Sloan Lane at the intersection will provide additional acces Scope Name: Bid Status Bid Number Jimmy Benoit VTN Nevada Mike Mamer CCPW Fast Trac Electric Traffic Signal System at Lake Mead Boulevard and Sloan Lane Traffic Signal at Lake Mead/ Sloan. 100% 100% 889 Feb May /8/ Jul /13/15 Oct /12/15 Oct /30/16 Traffic Improvements: Decatur/ Tropicana and Lindell/Tropicana 1 93 RTC Number 050Q-FTI ILC Amount $1,552, ILC Executed 07/09/2015 ILC Expiration 06/30/2020 Streets: NA Scope Name: Bid Status Bid Number TS & Road Improvements: Tropicana Ave, Lindell Rd to Decatur Blvd Traffic signal at Tropicana/Lindell, traffic signal modifications at Tropicana/Decatur. Additional dual left turn lanes will be installed on Tropicana Avenue at Decatur Boulevard % 100% 652 Jun 2015 Jimmy Benoit G.C. Wallace, Inc. Sep /4/15 Mike Mamer CCPW Fast Trac Electric Oct /9/15 Mar /27/16 Aug /24/16 Page 27 of 29

28 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Traffic Safety Improvements Package No RTC Number 050S ILC Amount $150, ILC Executed 12/14/2017 ILC Expiration 06/30/2022 Streets: NA Scope Name: Bid Status In Design Traffic Signal Systems at Various Locations No. 102 Bid Number? 0% 0% 969 Mar 2018 Jimmy Benoit Jun 2018 Louis Berger Group Mike Mamer Jul 2018 Sep 2018 Nov 2018 Tropicana Avenue, Hualapai Way to Fort Apache Road 2 22 RTC Number 006J-SB5 ILC Amount $320, ILC Executed 06/10/2010 ILC Expiration 06/30/2020 Streets: Curbs, gutters, sidewalks, pavement, and streetlights Scope Name: Bid Status In Number? Tropicana Avenue, Hualapai Way to Fort Apache Road Improvements to Tropicana Avenue, Hualapai Way to Fort Apache Road 90% 0% 785 Nov 2017 Brooke Prescia Feb 2018 Slater Hanifan Group Mike Mamer TBD Mar 2018 May 2018 Dec RTC Number 006J-FTI ILC Amount $10,000, ILC Executed 06/12/2014 ILC Expiration 07/01/2019 Streets: NA Scope Name: Bid Status In Design Bid Number Tropicana Avenue, Hualapai Way to Fort Apache Road Improvements to Tropicana Avenue, Hualapai Way to Fort Apache Road? 90% 0% 785 Nov 2017 Brooke Prescia Feb 2018 Slater Hanifan Group Mike Mamer TBD Mar 2018 May 2018 Dec 2018 Page 28 of 29

29 Regional Transportation Commission of Southern Nevada Project Status Report for Clark County Public Works January 02, 2018 Tropicana Avenue, Western 215 Beltway to Rainbow Boulevard ITS 1 56 RTC Number 144P ILC Amount $1,962, ILC Executed 06/13/2013 ILC Expiration 07/01/2018 Streets: NA Scope Name: Bid Status Reconciliation Durango Drive & Tropicana Avenue Fiber Optic Interconnect Systems Bid Number ITS infrastructure on Tropicana Avenue from the Western 215 Beltway to Rainbow Boulevard. id % 0% 848 Jun 2015 Jimmy Benoit C-A Group Sep /14/15 Robert McNamara CCPW TransCore ITS, LLC Nov /2/15 Feb 2016 Dec /9/17 Page 29 of 29

30

31

32

33

34

35

36

37

38

39

40

41

42

43

44

45

46

47

48

49

50

51

52

53

54

55

56

57

58

59

60

61

62

63

64

65

66

67

68

69

70

71

72 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/18 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Brooks Avenue North Fifth Street to Martin Luther King Boulevard PROJECT DESCRIPTION: This project consists of the design and construction of new and rehabilitated roadway improvements along Brooks Avenue to provide a completed connection from North Fifth Street to Martin Luther King Boulevard and a traffic signal at the intersection of Brooks Avenue and Martin Luther King Boulevard. The improvements include asphalt pavement, curb and gutter, sidewalk, LED street lights, utility relocations, signage and striping and other miscellaneous appurtenances. PROJECT NO: / 192 SID NUMBER: BID # TBD FUNDING SOURCE: RTC TOTAL COST: $4,734,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 9/8/16 11/1/17 65% ROW CLEARANCE 9/8/16 11/1/17 15% ENVIRONMENTAL CLEARANCE OPEN BIDS 12/1/17 12/1/17 0% CONSTRUCTION 2/1/18 6/30/18 0% ACCEPTANCE CONSULTANT/PROJECT MANAGER: CONTRACTOR: TBD COMMENTS: VTN Nevada / Robert Hosea, P.E. DELAYS: WORK COMPLETED THIS MONTH: Identified areas where right-of-way, construction easements and slope easements may be required. d the pavement replacement recommendations. Initiated design agreement with NV Energy to provide service to the traffic signal. WORK TO BE COMPLETED NEXT MONTH: Finalize areas where right-of-way, construction easements or slope easements will be required and continue the acquisition process. Execute design agreement with NV Energy to provide service to the traffic signal. Initiate the relocation of conflicting utility poles. PROJECT MANAGER: Clifford Moss PHONE NUMBER: (702)

73 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/18 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Carey Avenue Street Revere Street to Pecos Road PROJECT DESCRIPTION: This project consists of the design of approximately three miles of complete street improvements along Carey Avenue from Revere Street to Pecos Road. The project includes evaluation and design for vehicular traffic, transit traffic, bike traffic, pedestrian access, ADA accessibility, streetscape/landscape, right-of-way acquisition and relocation of utility lines. PROJECT NO: / 807 SID NUMBER: BID # TBD FUNDING SOURCE: RTC TOTAL COST: $500,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 11/13/14 3/31/17 90% ROW CLEARANCE 11/13/14 3/31/17 45% ENVIRONMENTAL CLEARANCE OPEN BIDS N/A N/A CONSTRUCTION N/A N/A ACCEPTANCE CONSULTANT/PROJECT MANAGER: Advantage Civil Design Group / Brandon Doty, P.E. CONTRACTOR: COMMENTS: TBD DELAYS: None. WORK COMPLETED THIS MONTH: Continued discussions regarding utility pole relocations, responsibilities and financial obligations. Continued preparation of legal descriptions for rights-of-way, easements and agreements to construct. WORK TO BE COMPLETED NEXT MONTH: Continue negotiations with dry utilities, Continue working on obtaining required rights-of-way, easements and rights-of-entry. PROJECT MANAGER: Clifford Moss, P.E. PHONE NUMBER: (702)

74 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/18 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Commerce Street Duchess Avenue to Cheyenne Avenue PROJECT DESCRIPTION: This project consists of the design and construction of new and rehabilitated roadway improvements along Commerce Street to provide a completed roadway from Duchess Avenue to Cheyenne Avenue. The improvements include asphalt pavement, curb and gutter, sidewalk, LED street lights, utility relocations, signage and striping and other miscellaneous appurtenances. PROJECT NO: / 933 SID NUMBER: BID # TBD FUNDING SOURCE: RTC TOTAL COST: $1,484,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 7/17/17 12/1/17 40% ROW CLEARANCE 7/17/17 12/1/17 15% ENVIRONMENTAL CLEARANCE OPEN BIDS 1/15/18 1/15/18 0% CONSTRUCTION 2/1/18 6/30/18 0% ACCEPTANCE CONSULTANT/PROJECT MANAGER: CONTRACTOR: TBD COMMENTS: VTN Nevada / Robert Hosea, P.E. DELAYS: WORK COMPLETED THIS MONTH: Identified areas where right-of-way, construction easements and slope easements may be required. d the pavement replacement recommendations. WORK TO BE COMPLETED NEXT MONTH: Finalize areas where right-of-way, construction easements or slope easements will be required and continue the acquisition process. Initiate the relocation of conflicting utility poles. PROJECT MANAGER: Clifford Moss PHONE NUMBER: (702)

75 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/18 REVIEW PERIOD FOR: 12/1/ /31/2017 PROJECT: Decatur Blvd Sidewalk Project PROJECT DESCRIPTION: New concrete sidewalk on the east side of Decatur Blvd between Lone Mountain Rd and Craig Rd, new ADA access ramps, relocation of existing signage, removal and replacement of existing landscaping, relocation and repair of existing irrigation, construction of retaining walls, and all other appurtenances as required. PROJECT NO: / 007N-FTI SID NUMBER: BID # 1482 FUNDING SOURCE: FRI TOTAL COST: $204,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 11/24 11/ % ROW CLEARANCE 7/ / % ENVIRONMENTAL CLEARANCE OPEN BIDS 1/2016 3/ % CONSTRUCTION 5/31/ /20/ % ACCEPTANCE 7/19/17 7/19/17 100% CONSULTANT/PROJECT MANAGER: Stanley Consultants/ Helena Murvosh CONTRACTOR: Las Vegas Paving COMMENTS: The project s plans and specifications have been consolidated with the Valley Sawtooth Infill Project for bidding in a single contract DELAYS: None WORK COMPLETED THIS MONTH: Worked on closing RTC ILC.. WORK TO BE COMPLETED NEXT MONTH: Close RTC interlocal contracts. PROJECT MANAGER: John Fitch P.E. PHONE NUMBER:

76 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/ /31/2017 PROJECT: Losee, Craig to CC-215 PROJECT DESCRIPTION: This project will consist of six travel lanes with traffic control devices, curb and gutter, sidewalks, LED streetlights, and localized and regional drainage improvements between Craig Road and the Northern Beltway. PROJECT NO: CNLV 10335; RTC 035E-SB5 / 035E-FTI SID NUMBER: N/A BID # 1432 FUNDING SOURCE: RTC SB5/FRI TOTAL COST: $17,157,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 09/23/10 2/20/ % ROW CLEARANCE 6/1/13 4/30/14 100% ENVIRONMENTAL CLEARANCE 100% OPEN BIDS 2/23/14 6/30/14 100% CONSTRUCTION 7/14/14 11/18/16 100% ACCEPTANCE 11/18/16 12/7/16 100% CONSULTANT/PROJECT MANAGER: 4Leaf/Clint Stay CONTRACTOR: Aggregate SWR COMMENTS: DELAYS: WORK COMPLETED THIS MONTH: Worked on closing RTC ILC. WORK TO BE COMPLETED NEXT MONTH: Close RTC ILC.. PROJECT MANAGER: Clint Fujii, P.E. PHONE NUMBER: (702)

77 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/18 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Las Vegas Boulevard Evans Avenue to Pecos Road PROJECT DESCRIPTION: Las Vegas Boulevard, Evans Avenue to Pecos Road. The improvements include design of improvements, construction, and installation of aggregate base, asphalt concrete roadway and median islands of that discourage jaywalking; and other appurtenances as may be necessary to construct a complete and functional project. PROJECT NO: / 779 SID NUMBER: BID # FUNDING SOURCE: RTC TOTAL COST: $1,517,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 8/1/2014 1/31/ % ROW CLEARANCE N/A 0 0 ENVIRONMENTAL CLEARANCE N/A 0 OPEN BIDS 5/18/2016 5/18/ % CONSTRUCTION 8/23/2016 4/20/ % ACCEPTANCE 4// /31/2017 0% CONSULTANT/PROJECT MANAGER: City of North Las Vegas CONTRACTOR: Addison, Inc. COMMENTS: Non-Binding Mediation was held on September 13, CNLV and are still arbitrating this project. DELAYS: WORK COMPLETED THIS MONTH: Remainder of project close out documents received, but some are tied to on-going Arbitration proceedings. NDOT s Punch List pending. Arbitration ongoing. WORK TO BE COMPLETED NEXT MONTH: Hopefully arbitration process and financial settlement anticipated to be completed next month. PROJECT MANAGER: Clint Fujii, P.E. PHONE NUMBER: (702)

78 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: North 5 th Street, Carey to Losee (Phase 1C) PROJECT DESCRIPTION: This segment of the limited access 150-foot super arterial will construct at an above grade crossing over Interstate I-15 extending from Carey Avenue to just north of the Union Pacific Railroad. The haunched girder bridge type shall include 3-lanes of travel in each direction with a dedicated transit lane along with pedestrian access on the east half of the bridge section. PROJECT NO: 10179C / RTC No. 149D-SB5 SID NUMBER: BID # 1381 FUNDING SOURCE: RTC TOTAL COST: $30,000,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN April of 2006 October ROW CLEARANCE January 2008 December ENVIRONMENTAL CLEARANCE June 2008 December OPEN BIDS October 2010 February CONSTRUCTION June 2011 December ACCEPTANCE January 2008 CONSULTANT/PROJECT MANAGER: Louis Berger Group/Roger Patton, PE CONTRACTOR: COMMENTS: Target Construction, Inc. ly complete. Waiting on contractor Lien releases in order to issue the Notice of. Legal issues with subcontractors and contractor. DELAYS: legal issues have stopped the project from final close-out process. WORK COMPLETED THIS MONTH: Project interlocal on hold until all legal issues are resolved. WORK TO BE COMPLETED NEXT MONTH: Waiting for information on lien releases. PROJECT MANAGER: Dale Daffern, P.E. PHONE NUMBER:

79 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/18 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: North 5 th Street, Losee to Cheyenne, Phase 1D PROJECT DESCRIPTION: Acquisition of right-of-way includes the segment from Losee Road to Cheyenne Avenue. PROJECT NO: 10179D RTC No. 149E-SB5 SID NUMBER: N/A BID # N/A FUNDING SOURCE: RTC TOTAL COST: TBD SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN ROW CLEARANCE 11/21/12 2/29/17 90% ENVIRONMENTAL CLEARANCE OPEN BIDS CONSTRUCTION ACCEPTANCE Lorena Candelario, SR/WA, Manager of Real Property CONSULTANT/PROJECT MANAGER: Services CONTRACTOR: COMMENTS: ROW Certification was completed June 25, DELAYS: None at this time. WORK COMPLETED THIS MONTH: Continue to work with City Attorney s Office and outside counsel on 5 th & Brook, LLC property condemnation. WORK TO BE COMPLETED NEXT MONTH: Continue to assist City Attorney s Office with any research, document preparation and exhibits for 5 th & Brooks, LLC condemnation case. PROJECT MANAGER: Lorena Candelario PHONE NUMBER: (702)

80 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/18 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: North 5 th Street, Carey Avenue to Colton Avenue Phase 1D PROJECT DESCRIPTION: The improvements include bridge structures over I-15 and the Union Pacific Railroad with up to six travel lanes, two dedicated transit lanes, drainage facilities, lighting, signing, traffic control devices, curb, gutter, sidewalks, streetlights, traffic signals, utility relocations, and other appurtenances as may be necessary to construct the project. PROJECT NO: 10179D SID NUMBER: BID # 1445 FUNDING SOURCE: RTC TOTAL COST: $23,450, SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN ROW CLEARANCE ENVIRONMENTAL CLEARANCE OPEN BIDS 3/19/14 5/07/14 100% CONSTRUCTION 9/02/14 5/09/16 100% ACCEPTANCE 5/09/16 1/18/17 100% CONSULTANT/PROJECT MANAGER: CONTRACTOR: Las Vegas Paving COMMENTS: Atkins North America/Cassandra Watson-Mihelcic, P.E. DELAYS: WORK COMPLETED THIS MONTH: Construction work is complete. WORK TO BE COMPLETED NEXT MONTH: Project funding closeout in process. PROJECT MANAGER: Clint Fujii, P.E. PHONE NUMBER: (702)

81 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: North 5 th Street, Alexander to Centennial Parkway (Infill / Sawtooth) PROJECT DESCRIPTION: This project consists of improvements to N. 5 th Street, Alexander Road to Centennial Parkway. The improvements will include a minimum four travel lanes with traffic control devices, localized drainage improvements, miscellaneous curb and gutter, sidewalks, pavement markings and striping, and other appurtenances as may be necessary to construct a complete and functional project. PROJECT NO: / 753 SID NUMBER: BID # 1442 FUNDING SOURCE: RTC TOTAL COST: $2,335,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 6/19/13 12/28/13 100% ROW CLEARANCE 6/19/13 12/28/13 100% ENVIRONMENTAL CLEARANCE N/A OPEN BIDS 02/12/14 02/12/14 100% CONSTRUCTION 08/18/14 4/30/17 100% ACCEPTANCE 7/19/17 100% CONSULTANT/PROJECT MANAGER: City of North Las Vegas CONTRACTOR: COMMENTS: Aggregate Industries DELAYS: WORK COMPLETED THIS MONTH: Worked on close out of RTC ILC. WORK TO BE COMPLETED NEXT MONTH: Close RTC ILC. PROJECT MANAGER: John Fitch P.E. PHONE NUMBER: (702)

82 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: North Las Vegas Pedestrian Upgrades at Donna Street & Tonopah Avenue PROJECT DESCRIPTION: The design and construction of pedestrian safety and traffic calming improvements on Donna Street and Tonopah Avenue fronting two schools. The basic improvements will provide school safety improvements at McCall Elemental and J.D. Smith Middle School. PROJECT NO: / 178G-FTI SID NUMBER: BID # 1518 FUNDING SOURCE: FTI TOTAL COST: $908,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 4/2016 4/ % ROW CLEARANCE ENVIRONMENTAL CLEARANCE OPEN BIDS 5/2017 7/ % CONSTRUCTION 12/2017 1/2018 5% ACCEPTANCE CONSULTANT/PROJECT MANAGER: CONTRACTOR: Muller Construction COMMENTS: HDR Engineering / Venu Parimi, P.E. DELAYS: Due to circumstances unrelated to this project, the has requested that the is delayed until December. WORK COMPLETED THIS MONTH: Preconstruction Meeting was held on November 21, The City has issued a for December 4, 2017 WORK TO BE COMPLETED NEXT MONTH: Begin Construction in Early December will proceed on all aspects of the project due to the compressed two month construction schedule. PROJECT MANAGER: Dave Tanner PHONE NUMBER:

83 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/18 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Rapid Flashing Pedestrian Crossings PROJECT DESCRIPTION: This project consists of the design and construction of rapid flashing pedestrian beacons with advanced warning devices and any other appurtenances as may be necessary to construct a complete and functional project at the intersections of Alexander Road and Arcata Way, Centennial Parkway and Bruce Street, Centennial Parkway and Donna Street, Centennial Parkway and Goldfield Street, and at North 5 th Street and the Las Vegas Wash (North of Craig Road). Two additional intersections were added to this project. They were Brooks Avenue and Martin Luther King Boulevard and June Avenue and Martin Luther King Boulevard. PROJECT NO: / 773 SID NUMBER: BID # $178, FUNDING SOURCE: RTC TOTAL COST: $474,075 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 8/1/14 7/10/15 100% ROW CLEARANCE ENVIRONMENTAL CLEARANCE N/A OPEN BIDS 7/14/15 7/14/15 100% CONSTRUCTION 12/14/15 1/1/ % ACCEPTANCE 11/28/16 12/21/ % CONSULTANT/PROJECT MANAGER: City of North Las Vegas / Clint Fujii, P.E. CONTRACTOR: MC4 Construction COMMENTS: DELAYS: WORK COMPLETED THIS MONTH: Worked on close out of RTC ILC. WORK TO BE COMPLETED NEXT MONTH: Close RTC ILC. PROJECT MANAGER: Clint Fujii, P.E. PHONE NUMBER: (702)

84 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/1/2018 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Gilmore Avenue Simmons Street to Allen Lane PROJECT DESCRIPTION: This project consists of all improvements associated with the roadway improvements of Gilmore Avenue to provide a fully completed connection from Simmons Street to Allen Lane. The improvements include asphalt pavement, curb and gutter, sidewalk, Light Emitting Diode (LED) streetlights, utility relocations, signage and striping, and any other miscellaneous appurtenances to complete the project. PROJECT NO: SID NUMBER: BID # FUNDING SOURCE: RTC TOTAL COST: $1,000,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 7/1/2017 7/1/2018 0% ROW CLEARANCE 7/1/2017 7/1/2018 0% ENVIRONMENTAL CLEARANCE N/A OPEN BIDS 8/1/ /1/2018 0% CONSTRUCTION 12/1/ /1/2019 0% ACCEPTANCE 06/1/ /1/2019 0% CONSULTANT/PROJECT MANAGER: TBD CONTRACTOR: TBD COMMENTS: DELAYS: WORK COMPLETED THIS MONTH: Project has been assigned. SOQ s were reviewed and Collins Engineering was selected as the design consultant has been chosen. Agreement has been negotiated and agenda item prepared. WORK TO BE COMPLETED NEXT MONTH: Council Agenda Item goes to Council on December 20. PROJECT MANAGER: Robert Huggins, P.E. PHONE NUMBER:

85 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/ /1/17 12/31/17 REVIEW PERIOD FOR: PROJECT: Las Vegas Boulevard Improvements (Tonopah Avenue to Carey Avenue) PROJECT DESCRIPTION: With the relinquishment of the R/W from NDOT to the City, the project will improve the section to provide for a complete street section that includes a landscape buffer between pedestrian sidewalks with vehicular traffic. The area between Tonopah and Lake Mead South will reduce the lane usage to one lane of travel in each direction. The section between Lake Mead South to Carey Avenue will re-capture the existing R/W and provide for median island landscaping, enhanced sidewalk width, and landscape buffer, and other sidewalk related features. PROJECT NO: SID NUMBER: N/A BID # TBD FUNDING SOURCE: RTC TOTAL COST: $15M SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 12/10/2014 3/1/ % ROW CLEARANCE 11/1/2018 1/18/2018 0% ENVIRONMENTAL CLEARANCE N/A OPEN BIDS 3/1/2018 4/9/ CONSTRUCTION 5/23/ /30/2019 0% ACCEPTANCE 12/1/2019 1/1/2020 0% CONSULTANT/PROJECT MANAGER: CONTRACTOR: TBD COMMENTS: CA Group, James Caviola Supporting Engineering Studies have been completed that include traffic, drainage, and geotechnical. Affected property owners were given an opportunity to discuss their concerns and were invited at the City office with one-on-one meetings where they were shown the proposed impacts to their parcel. DELAYS: NV Energy, SWG, Embarq, and Cox Cable relocations. Easement acquisitions. WORK COMPLETED THIS MONTH: The Preliminary Design Report (PDR) has been completed and adopted. The 70% submittal has been received and comments returned to CA Group. The Bidability/constructability review by CM Works has been completed and provided to CA Group. WORK TO BE COMPLETED NEXT MONTH: Consultant proceeding to 90% submittal. PROJECT MANAGER: Robert Huggins, PE, PTOE PHONE NUMBER:

86 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Sawtooth Roadways Improvements PROJECT DESCRIPTION: This project consists of infilling sawtooth roadways along the following four corridors: Commerce Street between Cheyenne Avenue and Centennial Parkway, Gowan Road between Allen Lane and Losee Road, Revere Street between Carey Avenue and Colton Road, and Alexander Road between North 5 th Street and Losee Road and a traffic signal at North 5 th Street and Centennial Parkway. The improvements will include traffic control devices, local drainage improvements, miscellaneous curb and gutter, sidewalks, pavement markings and striping, ADA Improvements, and other appurtenances as may be necessary to construct a complete and functional project. PROJECT NO: 10388A, 10388B, 10388C, 10388D, 10388E SID NUMBER: BID # FUNDING SOURCE: RTC TOTAL COST: $9,110,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 8/1/2014 2/1/18 85% ROW CLEARANCE 8/1/2014 2/1/18 65% ENVIRONMENTAL CLEARANCE N/A OPEN BIDS 9/1/2016 3/1/ % CONSTRUCTION 9/18/2017 9/18/ % ACCEPTANCE 9/01/ /1/2018 0% CONSULTANT/PROJECT MANAGER: CH2M Hill, Jacobs Engineering, Parsons Brinckerhoff, Kimley-Horn, and GCW. CONTRACTOR: COMMENTS: This Interlocal is divided up into 5 projects. Alexander & Commerce portions are in construction CM, John Fitch, (702) North 5 th Centennial is in design, PM Cliff Moss, (702) The PM for the other portions is listed below. DELAYS: WORK COMPLETED THIS MONTH: Alexander: Alexander construction is near completion. Change order approved by City Council to finish punch list items. Tand is awaiting push button extensions to be finish last CCA. Commerce: Finished paving sawtooth roads north of Craig and north of Azure. Finished RCP storm drain between Alexander Station Ave and Azure Ave. Began work on RCP storm drain between Lone Mountain and La Madre. Gowan: Reviewed bids and drafted an agenda item. Revere: Project is delayed by R/W acquisition and will now need some re-design for R/W that is unobtainable. Traffic Signal at N. 5 th : The 90% plans and specifications were submitted for review. WORK TO BE COMPLETED NEXT MONTH: Alexander: Finish CCA s and close out project construction. Commerce: Shift work on sawtooth roads between Craig and Cheyenne. Continue work on RCP between Lone Mountain and La Madre.. Gowan Construction Award Agenda Item presented to Council on December 20, Revere: Continue to redesign section of Revere to allow for unobtainable R/W. Traffic Signal at N. 5 th : the review of the 90% improvement plans and specifications and provide comments to the designers. PROJECT MANAGER: Robert Huggins, P.E. PHONE NUMBER:

87 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Traffic Signal Improvements PROJECT DESCRIPTION: This project consists of installing traffic signals at the following three intersections: Alexander Road/Clayton Street, Commerce Street/Ann Road, Commerce Street/Gowan Road, and Centennial Parkway and Bruce Street. The improvements will include traffic control devices, miscellaneous curb and gutter, sidewalks, pavement markings and striping, ADA Improvements, and other appurtenances as may be necessary to construct a complete and functional project. PROJECT NO: SID NUMBER: BID # 1485 FUNDING SOURCE: RTC TOTAL COST: $3,150,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 8/1/2014 7/ % ROW CLEARANCE 8/1/2014 9/1/ % ENVIRONMENTAL CLEARANCE N/A OPEN BIDS 9/1/ /1/ % CONSTRUCTION 8/14/2017 2/9/ % ACCEPTANCE 2/38/18 9/1/2018 0% CONSULTANT/PROJECT MANAGER: Slater Hanifan Group, Inc. CONTRACTOR: Las Vegas Electric COMMENTS: Dale Daffern is the design engineer for the additional signal at Bruce and Centennial due to the scope change for this project. DELAYS: WORK COMPLETED THIS MONTH: Finshed all underground at all three intersections. Set signal poles at Gowan and Commerce. Pulling wires to control cabinet at Commerce and Gowan. Traffic Signal for Centennial and Bruce Project: bids were reviewed and an agenda item was drafted recommending award to Las Vegas Electric. WORK TO BE COMPLETED NEXT MONTH Finish signal pole and signal arm installation at all three intersections. Pull wire to control cabinets at all three intersections. Traffic Signal for Centennial and Bruce Project: Anticipate City Council awarding construction contract and beginning preliminary construction. PROJECT MANAGER: John Fitch, P.E. PHONE NUMBER:

88 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Simmons, Cheyenne to Lone Mountain PROJECT DESCRIPTION: The project consists of full street improvements along the corridor to include up to 6 travel lanes, median island landscaping, curb and gutter, LED street lights, sidewalk, regional flood control improvements, a new traffic signal at Gowan Road, and utility relocations. The construction is split into 2 phases: (1) Roadway improvements between Cheyenne Ave. to Alexander Rd. and (2) Flood control improvements between Alexander Rd. to Red Coach Ave. PROJECT NO: CNLV 10339; RTC 148B-SB5 / 148D-FTI SID NUMBER: BID # 1433 FUNDING SOURCE: RTC SB5 TOTAL COST: $10,576,000 SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 10/12/10 (1) 2/10/14 (2) 3/30/14 (1) 100% (2) 100% ROW CLEARANCE 5/1/13 5/30/14 100% ENVIRONMENTAL CLEARANCE 11/30/13 100% OPEN BIDS (1) 3/2/14 (1) 6/30/14 (2) 4/1/14 (2) 7/31/14 100% CONSTRUCTION (1) 7/1/14 (1) 3/31/17 (1) 100% (2) 1/12/15 (2) 1/1/17 (2) 100% ACCEPTANCE (2)7/1/15 (2)12/1/16 CONSULTANT/PROJECT MANAGER: VTN / Robert Hosea CONTRACTOR: (1) Aggregate Industries (2) PACE Contracting COMMENTS: Consultant to repackage Ultimate Conditions pre final plan for the bidding and construction of the 20 X6 and 14 X6 RCBC from Alexander to the Gowan Outfall Channel. d negotiations with consultant to repackage project into 2 plan sets: (1) Roadway Improvements Phase 3 from Cheyenne to Alexander and (2) Combination Roadway & Flood Control from Alexander to Red Coach. This effort completed to accommodate availability of RFCD construction funds. DELAYS: None WORK COMPLETED THIS MONTH: Draft Notice of and agenda item for final acceptance. Anticipate the item will be heard at the December 6, 2017 Council Meeting. WORK TO BE COMPLETED NEXT MONTH: Begin RTC ILC close out process. PROJECT MANAGER: John Fitch P.E. PHONE NUMBER:

89 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/17 12/31/17 PROJECT: Tropical Parkway/Hollywood Boulevard Linn Lane to I-15 PROJECT DESCRIPTION: The design and construction of roadway infill/widening along Tropical Parkway and Hollywood Boulevard, from Linn Lane to I-15. This project will provide a design connection from Tropical Parkway and Linn Lane to Hollywood Boulevard and design a widened Hollywood Boulevard to the I-15. PROJECT NO: / 188B-FTI SWAP SID NUMBER: 65 BID # FUNDING SOURCE: FTI SWAP TOTAL COST: SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 4/2016 3/ % ROW CLEARANCE 9/2017 1/ % ENVIRONMENTAL CLEARANCE OPEN BIDS 3/2018 6/2018 CONSTRUCTION 7/2018 6/2019 ACCEPTANCE 6/2019 7/2019 N/A CONSULTANT/PROJECT MANAGER: CONTRACTOR: TBD COMMENTS: Louis Berger Group / Krishna Kumar (K.K.) DELAYS: Anticipate negotiating Amendment No. 1 and submitting for City Council approval to incorporate a sewer line to the design. This may delay the completion of the design up to 3 months. WORK COMPLETED THIS MONTH: d the 90% submittal review and returned comments to the consultant. Consultant began to address comments. Negotiations for TCE s continued. WORK TO BE COMPLETED NEXT MONTH: Anticipate submitting Amendment No. 1 to the design contract to Council to incorporate design of a branch sewer into the pre-final and 100% submittals. Consultant to address review comments and work on development of the pre-final submittal. Negotiations for TCE s along the corridor to continue. PROJECT MANAGER: Tom Brady, P.E. PHONE NUMBER:

90 Regional Transportation Commission Project Status Report ENTITY: City of North Las Vegas DATE PREPARED: 1/2/2018 REVIEW PERIOD FOR: 12/1/ /31/2017 PROJECT: PROJECT DESCRIPTION: Valley Cheyenne Avenue to Tropical Parkway The design and construction of improvements on Valley Drive, Cheyenne Avenue to Tropical Parkway. The improvements may include installation of aggregate bas, asphalt concrete roadway, pedestrian walk paths and other appurtenances as may be necessary to construct a function project. PROJECT NO: / 166B-FTI SID NUMBER: BID # 1482 FUNDING SOURCE: FRI TOTAL COST: SCHEDULE FOR COMPLETION START DATE END DATE COMPLETE (%) DESIGN 11/ / % ROW CLEARANCE 7/ / % ENVIRONMENTAL CLEARANCE OPEN BIDS 1/2016 3/ % CONSTRUCTION 5/31/16 2/24/ % ACCEPTANCE 7/19/17 7/19/17 100% CONSULTANT/PROJECT MANAGER: CONTRACTOR: Las Vegas Paving COMMENTS: Stanley Consultants / Helena Murvosh This project s plans and specifications have been consolidated with the Decatur Blvd Sidewalk Project for bidding in a single contract. DELAYS: None WORK COMPLETED THIS MONTH: Worked on closing RTC ILC. WORK TO BE COMPLETED NEXT MONTH: Close RTC ILC. PROJECT MANAGER: John Fitch, P.E. PHONE NUMBER:

91 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: January 9, 2018 REVIEW PERIOD FROM: December 1, 2017 TO: December 31, 2017 PROJECT: PUEBLO BLVD - NEWPORT DR TO WARM SPRINGS RD RTC# s 161B-FTI DESCRIPTION: REHABILITATION OF PUEBLO BLVD - NEWPORT DR TO WARM SPRINGS RD INCLUDING COMPLETE STREETS ELEMENTS PERCENT COMPLETE: Design 100% Construction 0% ESTIMATED COST OF PROJECT: $125,000 DESIGN SCHEDULE FOR COMPLETION: (s) DESIGN: October 2017 R/W CLEARANCES: ENVIR CLEARANCES: N/R N/R BIDS OPEN: N/R START CONSTRUCTION: CONSTRUCTION COMPLETE: N/R N/R CONSULTANT/PROJECT MANAGER: STANTEC / MR CARY BAIRD CONSTRUCTION PRIME CONTRACTOR: N/A DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: working on project closeout WORK TO BE COMPLETED DURING NEXT MONTH: project closeout PROJECT MANAGER: Matt Roybal, PE PHONE NUMBER: Roybal 1 of 7

92 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: January 9, 2018 REVIEW PERIOD FROM: December 1, 2017 TO: December 31, 2017 PROJECT: WARM SPRINGS ROAD, LAKE MEAD PKWY TO RACETRACK RD 046K-FTI DESCRIPTION: PROJECT MAY RESULT IN A ROAD DIET TO REDUCE TRAVEL LANES TO 4 AND PROVIDE ADDITIONAL SPACE FOR SIDEWALK AND TRAIL IMPROVEMENTS TO IMPROVE NEIGHBORHOOD AND SCHOOL ACCESS. PROJECT WILL ALSO PROVIDE COMPLETE STREET ELEMENTS OFF-STREET TRAIL, ON-STREET BIKE LANES AND IMPROVED PED AND BIKE CROSSINGS. PERCENT COMPLETE: Design 90% ESTIMATED COST OF PROJECT: $150, Construction 0% SCHEDULE FOR COMPLETION: (s) DESIGN: November 2017 R/W CLEARANCES: ENVIR CLEARANCES: N/A N/R BIDS OPEN: N/A START CONSTRUCTION: CONSTRUCTION COMPLETE: N/A N/A CONSULTANT/PROJECT MANAGER: Stanley Consultants, Inc. Don Davis, P.E. CONSTRUCTION PRIME CONTRACTOR: N/A DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Consultant working on final comments. WORK TO BE COMPLETED DURING NEXT MONTH: final comments PROJECT MANAGER: Matt Roybal, PE PHONE NUMBER: Roybal 2 of 7

93 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: January 9, 2018 REVIEW PERIOD FROM: December 1, 2017 TO: December 31, 2017 PROJECT: ANTHEM NEIGHBORHOOD REHABILITATION (RTC# 175A-FTI) and EASTERN/PECOS/BECKLER INTERSECTION (002AC-FTI) DESCRIPTION: REHABILITATION AND IMPROVEMENTS IN THE ANTHEM NEIGHBORHOOD. PERCENT COMPLETE: Design 100% ESTIMATED COST OF PROJECT: $3,025,000 Construction Sites 5,3,4 100% Site 2 80% Site 1 0% SCHEDULE FOR COMPLETION: (s) DESIGN: Site 1 June 2017; Site 2- May 2017 R/W CLEARANCES: ENVIR CLEARANCES: N/A N/R BIDS OPEN: Site 1 July 2017 Site 2 - May 2017 START CONSTRUCTION: Site 1 - Nov 2017 Site 2 July 2017 CONSTRUCTION COMPLETE: Site 1 Jun 2018; Site 2 Jan CONSULTANT/PROJECT MANAGER: Kimley Horn, Shannon Ahartz, PE. CONSTRUCTION PRIME CONTRACTOR: Mc4 for Sites 3 and 4; Wadley for Site 2; Mc4 for Site 1 DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Site 2 at Country Club Entrance paving on going. WORK TO BE COMPLETED DURING NEXT MONTH: Site 2 - install striping and project walk. Site 1 Beckler working on material procurement. PROJECT MANAGER: Matt Roybal, P.E. PHONE NUMBER: Roybal 3 of 7

94 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: January 9, 2018 REVIEW PERIOD FROM: December 1, 2017 TO: December 31, 2017 PROJECT: WEST HENDERSON ROADS; BERMUDA VOLUNTEER BLVD TO ST ROSE PARKWAY, BRUNER ROAD GILESPIE STREET TO EXECUTIVE AIRPORT DRIVE, AND GILESPIE STREET VOLUNTEER BLVD TO ST ROSE PARKWAY. (RTC# 175H-FTI and 175H) DESCRIPTION: Design of 4 lane roadway sections with the ability to widen to 6 lanes in certain areas. Incorporate complete streets elements as appropriate and feasible. PERCENT COMPLETE: Design 60% Construction 0% ESTIMATED COST OF PROJECT: $300,000 Design SCHEDULE FOR COMPLETION: (s) DESIGN: November 2017 R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: START CONSTRUCTION: Design Only CONSTRUCTION COMPLETE: CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: VTN TBD DELAYS OR PROBLEM AREAS: Annexation and ROW at Via Nobila WORK COMPLETED DURING CURRENT MONTH: TN preparing additional exhibits WORK TO BE COMPLETED DURING NEXT MONTH: PROJECT MANAGER: Matt Roybal, P.E. PHONE NUMBER: Roybal 4 of 7

95 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: January 9, 2018 REVIEW PERIOD FROM: December 1, 2017 TO: December 31, 2017 PROJECT: VALLE VERDE DRIVE, HORIZON RIDGE PARKWAY TO WARM SPRINGS ROAD (183A-FTI) DESCRIPTION: The project will evaluate and repair significant pavement deterioration to include new pavement, markings, continuous bike lanes and improved pedestrian facilities, including improved multi-modal access to the adjacent Pittman Wash Trail, Silver Springs Recreation Center, Gibson Elementary School and Greenspun Jr. High. PERCENT COMPLETE: Design - 95% ESTIMATED COST OF PROJECT: $2,500, Construction 0% SCHEDULE FOR COMPLETION: (s) DESIGN: November 2017 R/W CLEARANCES: N/R ENVIR CLEARANCES: N/R BIDS OPEN: January 2018 START CONSTRUCTION: March 2018 CONSTRUCTION COMPLETE: January 2019 CONSULTANT/PROJECT MANAGER: Horrocks Engineers / Lee Jacoby, P.E. CONSTRUCTION PRIME CONTRACTOR: TBD DELAYS OR PROBLEM AREAS: coordinating construction timing to not conflict Arroyo Grande WORK COMPLETED DURING CURRENT MONTH: Draft concept received to modify landscaping WORK TO BE COMPLETED DURING NEXT MONTH: Review concept internally and discuss options for final design. PROJECT MANAGER: Matt Roybal, P.E. PHONE NUMBER: Roybal 5 of 7

96 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: January 9, 2018 REVIEW PERIOD FROM: December 1, 2017 TO: December 31, 2017 PROJECT: ROMA HILLS (201A-FTI2) DESCRIPTION: Replace existing pavement and construct complete street elements as appropriate PERCENT COMPLETE: Design - 0% ESTIMATED COST OF PROJECT: $2,000, Construction 0% SCHEDULE FOR COMPLETION: (s) DESIGN: July 2017 R/W CLEARANCES: N/R ENVIR CLEARANCES: N/R BIDS OPEN: July 2018 CONSULTANT/PROJECT MANAGER: Stanley START CONSTRUCTION: October 2018 CONSTRUCTION COMPLETE: October 2019 CONSTRUCTION PRIME CONTRACTOR: TBD DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: finalized scope with the consultant WORK TO BE COMPLETED DURING NEXT MONTH: finalize fee PROJECT MANAGER: Matt Roybal, P.E. PHONE NUMBER: Roybal 6 of 7

97 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: January 9, 2018 REVIEW PERIOD FROM: December 1, 2017 TO: December 31, 2017 PROJECT: VIA NOBILA LAS VEGAS BLVD TO VIA INSPIRADA (199A-FTI2) DESCRIPTION: Right of way acquisition and up to four lanes of pavement on Via Nobila from Las Vegas Blvd. to Via Inspirada. Phase I of the project will include the right of way acquisition from Las Vegas Blvd. to Gilespie St. PERCENT COMPLETE: Design - 0% ESTIMATED COST OF PROJECT: $1,000, Construction 0% DESIGN: N/A SCHEDULE FOR COMPLETION: (s) R/W CLEARANCES: November 2017 ENVIR CLEARANCES: N/R BIDS OPEN: future START CONSTRUCTION: future CONSTRUCTION COMPLETE: future CONSULTANT/PROJECT MANAGER: Matt Roybal (inhouse coordination) CONSTRUCTION PRIME CONTRACTOR: future phase DELAYS OR PROBLEM AREAS: BLM annexation WORK COMPLETED DURING CURRENT MONTH: appraisals complete WORK TO BE COMPLETED DURING NEXT MONTH: acquire the property PROJECT MANAGER: Matt Roybal, P.E. PHONE NUMBER: Roybal 7 of 7

98 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: JANUARY 9, 2018 REVIEW PERIOD FROM: DECEMBER 1, 2017 TO: DECEMBER 31, 2017 PROJECT BASIC RD PACIFIC AVE TO BOULDER HWY (200A-FTI2) DESCRIPTION: REPLACE EXISTING PAVEMENT AND CONSTRUCT COMPLETE STREET ELEMENTS PERCENT COMPLETE: Design 30% Construction % ESTIMATED COST OF PROJECT: $2,000,000_ SCHEDULE FOR COMPLETION: (s) DESIGN: July 2018 R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: July 2018 START CONSTRUCTION: October 2018 CONSTRUCTION COMPLETE: October 2019 CONSULTANT/PROJECT MANAGER: CA Group Inc. CONSTRUCTION PRIME CONTRACTOR: DELAYS OR PROBLEM AREAS: None WORK COMPLETED DURING CURRENT MONTH: Received 30% plan submittal WORK TO BE COMPLETED DURING NEXT MONTH: Review and issue comments PROJECT MANAGER: RON MAURIZI PHONE NUMBER: M aurizi 1 of 2

99 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: JANUARY 9, 2018 REVIEW PERIOD FROM: DECEMBER 1, 2017 TO: DECEMBER 31, 2017 PROJECT COMPLETE STREETS 2018 CASSIA WAY (191-CSF) DESCRIPTION: TRAFFIC CALMONG AND COMPLETE STREET ELEMENTS ALONG CASSIA WAY PERCENT COMPLETE: Design 100% Construction 100% ESTIMATED COST OF PROJECT: $218,948_ SCHEDULE FOR COMPLETION: (s) DESIGN: January 2017 R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: August 2017 START CONSTRUCTION: October 2017 CONSTRUCTION COMPLETE: March 2018 CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: Ron Maurizi American Pavement Preservation DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Construction complete WORK TO BE COMPLETED DURING NEXT MONTH: Working on minor punch list items PROJECT MANAGER: RON MAURIZI PHONE NUMBER: M aurizi 2 of 2

100 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: DECEMBER 5, 2017 REVIEW PERIOD FROM: NOVEMBER 1, 2017 TO: NOVEMBER 30, 2017 PROJECT: CENTER STREET BOULDER HIGHWAY TO LAKE MEAD (RTC# 11B) DESCRIPTION: COMPLETE STREETS RECONSTRUCTION PERCENT COMPLETE: Design 100% Construction 25% ESTIMATED COST OF PROJECT: $3,300,000 RTC $9,400,000 CCRFCD SCHEDULE FOR COMPLETION: (s) DESIGN: May 2016 R/W CLEARANCES: December 2015 ENVIR CLEARANCES: December 2015 BIDS OPEN: March 2017 START CONSTRUCTION: June 2017 CONSTRUCTION COMPLETE: May 2018 CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: GC Wallace Las Vegas Paving DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Construction on going. WORK TO BE COMPLETED DURING NEXT MONTH: Continue construction. PROJECT MANAGER: Scott Fiedler PHONE NUMBER: (702) S:\STREETS\\TEMP\\01 January 2018\Status Reports\SCOTT F 2017.docx 1 of 7

101 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: DECEMBER 5, 2017 REVIEW PERIOD FROM: NOVEMBER 1, 2017 TO: NOVEMBER 30, 2017 PROJECT: APPALOOSA DR WAGONWHEEL TO EQUESTRIAN DESCRIPTION: Roadway improvements along Appaloosa from Wagonwheel to Equestrian. This project will coordinate storm drain improvements with roadway improvements and other appurtenances as may be necessary to construct a complete and functional Project. PERCENT COMPLETE: Design 100% Construction 25% ESTIMATED COST OF PROJECT: $1,000,000 RTC $572,000 CCRFCD SCHEDULE FOR COMPLETION: (s) DESIGN: Feb 2016 R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: March 2017 START CONSTRUCTION: June 2017 CONSTRUCTION COMPLETE: May 2018 CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: GC Wallace Las Vegas Paving DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Construction on going. WORK TO BE COMPLETED DURING NEXT MONTH: Continue construction. PROJECT MANAGER: Scott Fiedler PHONE NUMBER: (702) S:\STREETS\\TEMP\\01 January 2018\Status Reports\SCOTT F 2017.docx 2 of 7

102 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: DECEMBER 5, 2017 REVIEW PERIOD FROM: NOVEMBER 1, 2017 TO: NOVEMBER 30, 2017 PROJECT: STARR RD LAS VEGAS BLVD TO ST ROSE PARKWAY (152C-FTI, 152B-SB5) DESCRIPTION: Roadway construction. PERCENT COMPLETE: Design 100% ESTIMATED COST OF PROJECT: $4,500,000 Construction 90% SCHEDULE FOR COMPLETION: (s) DESIGN: 5/2016 R/W CLEARANCES: 9/2015 ENVIR CLEARANCES: 9/2015 BIDS OPEN: 6/2016 START CONSTRUCTION: 3/2017 CONSTRUCTION COMPLETE: 12/2017 CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: CA Group Las Vegas Paving DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Construction ongoing. WORK TO BE COMPLETED DURING NEXT MONTH: Continue construction. PROJECT MANAGER: Scott Fiedler PHONE NUMBER: (702) S:\STREETS\\TEMP\\01 January 2018\Status Reports\SCOTT F 2017.docx 3 of 7

103 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: DECEMBER 5, 2017 REVIEW PERIOD FROM: NOVEMBER 1, 2017 TO: NOVEMBER 30, 2017 PROJECT: HORIZON DRIVE; I-515 TO BOULDER HIGHWAY (RTC# 015M, 015R-FTI) DESCRIPTION: MILL AND OVERLAY OF TRAVEL LANES, WIDENING OF SIDEWALKS, AND INSTALLATION OF BIKE LANES. PERCENT COMPLETE: Design 100% ESTIMATED COST OF PROJECT: $3,234,000 Construction 0% SCHEDULE FOR COMPLETION: (s) DESIGN: 12/2016 R/W CLEARANCES: 8/2016 ENVIR CLEARANCES: BIDS OPEN: 12/2017 START CONSTRUCTION: 3/2018 CONSTRUCTION COMPLETE: 9/18 CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: Atkins TBD DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: d for bids. WORK TO BE COMPLETED DURING NEXT MONTH: bids PROJECT MANAGER: Scott Fiedler PHONE NUMBER: (702) S:\STREETS\\TEMP\\01 January 2018\Status Reports\SCOTT F 2017.docx 4 of 7

104 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: DECEMBER 5, 2017 REVIEW PERIOD FROM: NOVEMBER 1, 2017 TO: NOVEMBER 30, 2017 PROJECT MANAGER: Scott Fiedler PHONE NUMBER: PROJECT: ARROYO GRANDE PKWY, HORIZON RIDGE PKWY TO SUNSET RD (175C-FTI) DESCRIPTION: This project will result in the rehabilitation/reconstruction of Arroyo Grande Boulevard from Horizon Ridge Parkway to Sunset Road. The project will evaluate and repair significant pavement deterioration to include new pavement, markings, continuous bike lanes and improved pedestrian facilities, including improved multi-modal access to the adjacent Arroyo Grande Sports Complex and Green Valley High School. The project will also evaluate and mitigate ground water intrusion problems within and adjacent to the corridor including the intersections of Arroyo Grande / Mayan, Helmsdale / Harwick and Sunset Road east of Scimitar. The project will incorporate complete streets elements as appropriate and feasible. PERCENT COMPLETE: Design - 95% ESTIMATED COST OF PROJECT: $7,471,000 Construction 0% SCHEDULE FOR COMPLETION: (s) DESIGN: Fox Butte Court: (100%), Arroyo Grande: November 2015 R/W CLEARANCES: N/R ENVIR CLEARANCES: N/R BIDS OPEN: June 2017 START CONSTRUCTION: December 2017 CONSTRUCTION COMPLETE: July 2018 CONSULTANT/PROJECT MANAGER: Jacobs Engineering Group / Ben Taylor, P.E. CONSTRUCTION PRIME CONTRACTOR: Las Vegas Paving DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Working signal plans for Wigwam and Arroyo Grande. WORK TO BE COMPLETED DURING NEXT MONTH: Project awarded to Las Vegas Paving. S:\STREETS\\TEMP\\01 January 2018\Status Reports\SCOTT F 2017.docx 5 of 7

105 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: DECEMBER 5, 2017 REVIEW PERIOD FROM: NOVEMBER 1, 2017 TO: NOVEMBER 30, 2017 PROJECT: STEPHANIE ST I215 TO DRAGONRIDGE COUNTRY CLUB (097F-FTI2) DESCRIPTION: Replace existing pavement and construct complete street elements as feasible PERCENT COMPLETE: Design 0% ESTIMATED COST OF PROJECT: $2,000,000 Construction 0% SCHEDULE FOR COMPLETION: (s) DESIGN: September 2018 R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: September 2018 START CONSTRUCTION: November 2018 CONSTRUCTION COMPLETE: December 2019 CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: Horricks TBD DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Met with consultant to discuss scoping WORK TO BE COMPLETED DURING NEXT MONTH: Finalize scoping and prepare engineering services agreement PROJECT MANAGER: Scott Fiedler PHONE NUMBER: (702) S:\STREETS\\TEMP\\01 January 2018\Status Reports\SCOTT F 2017.docx 6 of 7

106 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: DECEMBER 5, 2017 REVIEW PERIOD FROM: NOVEMBER 1, 2017 TO: NOVEMBER 30, 2017 PROJECT: SUNRIDGE HEIGHTS PKWY EXECUTIVE AIRPORT TO SEVEN HILLS DR DESCRIPTION: design and construction of roadway improvements including up to 6 travel lanes, lighting, striping, traffic signals, and drainage. Phase 1 of the project will include preliminary design and coordination with adjacent developers and will be constructed between Seven Hills and Maryland Pkwy. Phase 2 will be constructed between Maryland Pkay and Executive Airport. The project will incorporate complete streets elements as appropriate and feasible. PERCENT COMPLETE: Design 90% ESTIMATED COST OF PROJECT: $6,270,000 Construction % SCHEDULE FOR COMPLETION: (s) DESIGN: July 2018 R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: December 2018 START CONSTRUCTION: March 2018 CONSTRUCTION COMPLETE: September 2018 CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: Advantage Civil Design Group TBD DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Returned 90% comments on Phase 1 consultant. WORK TO BE COMPLETED DURING NEXT MONTH: Consultant to prepare final bid documents. PROJECT MANAGER: Scott Fiedler PHONE NUMBER: (702) S:\STREETS\\TEMP\\01 January 2018\Status Reports\SCOTT F 2017.docx 7 of 7

107 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: JANUARY 9, 2018 REVIEW PERIOD FROM: DECEMBER 1, 2017 TO: DECEMBER 31, 2017 PROJECT: WATER ST MAJOR AVE TO LAKE MEAD PARKWAY (171B-FTI2) DESCRIPTION: ROADWAY IMPROVEMENTS ALONG WATER STREET PERCENT COMPLETE: Design 100% ESTIMATED COST OF PROJECT: $4,400,000 Construction 0% SCHEDULE FOR COMPLETION: (s) DESIGN: May 2018 R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: November 2018 START CONSTRUCTION: January 2018 CONSTRUCTION COMPLETE: October 2018 CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: CA Group Inc. TBD DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: were received WORK TO BE COMPLETED DURING NEXT MONTH: Move to award construction to apparent low bidder PROJECT MANAGER: Scott Jarvis PHONE NUMBER: Jarvis 1 of 5

108 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: JANUARY 9, 2018 REVIEW PERIOD FROM: DECEMBER 1, 2017 TO: DECEMBER 31, 2017 PROJECT: HORIZON DRIVE; PACIFIC AVENUE TO HORIZON RIDGE PARKWAY (RTC# 15N) DESCRIPTION: FEDERAL FUND MATCH FOR THE CONSTRUCTION OF ADDITIONAL MAIN LINE RAMPS, TURN LANES, AND ROADWAY MODIFICTIONS TO ACCOMMODATE REQUIRED CAPACITY IMPROVEMENTS USING Q10 FUNDS. PERCENT COMPLETE: Design 100% ESTIMATED COST OF PROJECT: $250,000 Construction 100% SCHEDULE FOR COMPLETION: (s) DESIGN: November 2013 R/W CLEARANCES: December 2011 ENVIR CLEARANCES: BIDS OPEN: March 2014 START CONSTRUCTION: June 2014 CONSTRUCTION COMPLETE: CONSULTANT/PROJECT MANAGER: CONSTRUCTION PRIME CONTRACTOR: Atkins Aggregate Industries DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Alternative of signal timing completed. Observing effectiveness of new timing. WORK TO BE COMPLETED DURING NEXT MONTH: Continue optimization PROJECT MANAGER: Scott Jarvis PHONE NUMBER: Jarvis 2 of 5

109 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: JANUARY 9, 2018 REVIEW PERIOD FROM: DECEMBER 1, 2017 TO: DECEMBER 31, 2017 PROJECT: DOWNTOWN HENDERSON COMPLETE STREETS (RTC# 176A-FTI) DESCRIPTION: DESIGN AND CONSTRUCTION OF REHABILITATION IMPROVEMENTS TO THE DOWNTOWN BUSINESS AREA. PERCENT COMPLETE: Design 100% ESTIMATED COST OF PROJECT: $7,000,000 Construction 75% SCHEDULE FOR COMPLETION: (s) DESIGN: November 2014 R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: START CONSTRUCTION: March 2017 CONSTRUCTION COMPLETE: CONSULTANT/PROJECT MANAGER: Steve Wyszomirski/ CA Group CONSTRUCTION PRIME CONTRACTOR: Las Vegas Paving DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Continuing installation of curb and gutter and sidewalks in various locations. WORK TO BE COMPLETED DURING NEXT MONTH: Continue construction. PROJECT MANAGER: Scott Jarvis PHONE NUMBER: Jarvis 3 of 5

110 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: JANUARY 9, 2018 REVIEW PERIOD FROM: DECEMBER 1, 2017 TO: DECEMBER 31, 2017 PROJECT: I515/I215 INTERCHANGE IMPROVEMENTS (100D-FTI) DESCRIPTION: complete design and environmental required to construct traffic capacity improvements and all related appurtenances at I-515/I-215 Interchange Improvements from Galleria Drive to Horizon Drive on the I-515 and from Fiesta Henderson Boulevard to Stephanie Street on the I-215. PERCENT COMPLETE: Design % ESTIMATED COST OF PROJECT: $2,000,000 Construction NA DESIGN: SCHEDULE FOR COMPLETION: (s) R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: NA START CONSTRUCTION: NA CONSTRUCTION COMPLETE: NA CONSULTANT/PROJECT MANAGER: TBD CONSTRUCTION PRIME CONTRACTOR: NA DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Coordination with NDOT on scope of project and coordination opportunities. Preparing RSOQ for environmental needs. WORK TO BE COMPLETED DURING NEXT MONTH: Issue RSOQ PROJECT MANAGER: Scott Jarvis PHONE NUMBER: Jarvis 4 of 5

111 REGIONAL TRANSPORTATION COMMISSION OF SOUTHERN NEVADA PROJECT STATUS REPORT ENTITY: CITY OF HENDERSON DATE: JANUARY 9, 2018 REVIEW PERIOD FROM: DECEMBER 1, 2017 TO: DECEMBER 31, 2017 PROJECT: EASTERN AVENUE COORIDOR STUDY (002AC-FTI2) DESCRIPTION: This phase of the project will consist of a corridor study including a progression analysis and design alternatives to address traffic congestion and safety, in particular at the intersection of St. Rose Pkwy and Eastern Ave. PERCENT COMPLETE: Design % ESTIMATED COST OF PROJECT: $500,000 Construction NA DESIGN: SCHEDULE FOR COMPLETION: (s) R/W CLEARANCES: ENVIR CLEARANCES: BIDS OPEN: NA START CONSTRUCTION: NA CONSTRUCTION COMPLETE: NA CONSULTANT/PROJECT MANAGER: TBD CONSTRUCTION PRIME CONTRACTOR: NA DELAYS OR PROBLEM AREAS: WORK COMPLETED DURING CURRENT MONTH: Preparing RSOQ for consultant selection WORK TO BE COMPLETED DURING NEXT MONTH: Issue RSOQ PROJECT MANAGER: Scott Jarvis PHONE NUMBER: Jarvis 5 of 5

112

113

114

115

116